Notwithstanding the provisions of paragraph 154, if any future specified...
- Cooperate and give notice for urgent emergency work
UK Statutory Instrument
2023
United Kingdom
The Awel y Môr Offshore Wind Farm Order 2023
At a glance
What's here
3 compliance obligations
What this Act requires
Sections that create concrete duties on businesses or carry penalties. Procedural and definitional sections are folded into the “Browse other sections” expander at the bottom of each group. Click any section title to read the source text on legislation.gov.uk.
Schedules
Works on Company cables
- Follow procedure before carrying out cable works within 250 metres of undertaker cables
Browse 218 other Schedules — structural / supplementary
Time limits
Code of construction practice
Highway accesses
Onshore archaeology
Landscape and Ecology management plan
European protected species onshore
Construction hours
Surface and foul water drainage
Restoration of land used temporarily for construction
Control of noise during operational stage
Control of operational artificial light emissions
Offshore design parameters
Skills and Employment Strategy
Offshore decommissioning
Onshore decommissioning
Great Dun Fell and St Annes Primary Radar Mitigation Scheme
Landscape enhancement scheme
Wake effects
Requirement for written approval
Amendments to approved details
Aviation safety
Offshore Noise
Stages of authorised development
Substation works
Detailed design parameters onshore
Provision of landscaping
Implementation and maintenance of landscaping
Compensation enactments
Section 22 (interests omitted from purchase) of the 1965 Act...
For Schedule 2A of the 1965 Act substitute— SCHEDULE 2A...
(1) Without limitation on the scope of paragraph 1, the...
(1) Without limitation on the scope of paragraph 1, the...
Application of Part 1 of the 1965 Act
References in the 1965 Act to land are, in the...
For section 7 (measure of compensation in case of severance)...
The following provisions of the 1965 Act (which state the...
Section 11 (powers of entry) of the 1965 Act is...
Section 20 (tenants at will, etc.) of the 1965 Act...
The provisions of this Part have effect unless otherwise agreed...
Miscellaneous
In this Part— “alternative apparatus” means alternative apparatus adequate to...
On street apparatus and offshore works
Apparatus in streets subject to temporary restriction
Acquisition of land
Removal of apparatus
Facilities and rights for alternative apparatus
Retained apparatus
Expenses and costs
(1) Subject to sub-paragraph (2) and (3) if by reason...
Enactments and agreements
For the protection of DC referred to in this Part...
Application
Interpretation
Approvals
(1) Prior to the commencement of the works the undertaker...
No crossing is to take place until a monitoring regime...
Approval under this Part may be sought in one or...
Any approval of the WM under this Part may be...
The undertaker must contact any owners or operators of apparatus...
The undertaker must pay a fee of £250 to the...
Indemnity
In this Part of this Schedule: “accessories” has the same...
The undertaker (or any person carrying out works on its...
Traffic management
The undertaker must execute the works in strict accordance with...
Inspections
Exercise of the right to inspect under paragraph 123 must...
If required by the WM, the undertaker must provide link...
(1) The undertaker must compensate the WM in respect of...
Reinstatement
(1) Where, in the reasonable opinion of the WM, any...
Any and all costs associated with the reinstatement work will...
(1) Regardless of any provision in this Order or anything...
Notice of completion of Works
The undertaker must supply the WM with as built records...
The undertaker must submit a Geotechnical Feedback Report (GFR as...
After the apparatus has been placed, the undertaker must not...
Arbitration
Notices
Cease of Use or Abandonment
If the apparatus is abandoned or the consent is surrendered...
If the undertaker proposes to part with his interest in...
Maintenance
Precedence of the WIA 1991
Application
Interpretation
Requirement for approval of method statement and surveys
If by the expiry of 28 days, beginning on the...
The undertaker must, at its own cost, carry out all...
In granting its approval (or deemed approval) of the method...
The undertaker must use all reasonable endeavours to ensure the...
Requirement for notification of start of works
Carrying out of works
The undertaker must ensure that the specified work are carried...
Protection of DC apparatus
Any contractor and/or subcontractor used by the undertaker for the...
Either during the installation or as soon as practicable after...
The undertaker must provide the Company with the actual as-laid...
The undertaker must ensure that the risk of dropped object,...
Future specified work
Subject to paragraphs 154 and 155, where the undertaker requires...
Restrictions on anchors and moorings
Indemnity and liabilities
Suspension of works
The undertaker is responsible for the recovery or removal and...
(1) In the event of the undertaker being liable for...
In the event of the undertaker being liable for damage...
The undertaker must use reasonable endeavours to procure that any...
Representatives
Insurance
Force majeure
Costs and expenses
Arbitration
Arbitration
Co-Operation
Emergency Works
Damage to DC apparatus
In this Part— “alternative apparatus” means alternative apparatus adequate to...
Application
Interpretation
Interaction with the Bodelwyddan Project
National Grid connection works
(1) Before beginning to construct any National Grid connection works,...
(1) Any approval of National Grid required under this Schedule—...
(1) The undertaker must give to National Grid not less...
On Street Apparatus
Apparatus of National Grid in streets subject to temporary stopping up
Protective works to buildings
On street apparatus and offshore works
Acquisition of land
Removal of apparatus
Facilities and rights for alternative apparatus
Retained apparatus: Protection of National Grid as Electricity Undertaker
Expenses
Indemnity
Enactments and agreements
Co-operation
Access
Arbitration
Acquisition of land
Notices
Application
Interpretation
On Street Apparatus
Acquisition of land
Removal of apparatus
Facilities and rights for alternative apparatus
Retained apparatus: Protection of SP Manweb as Electricity Undertaker
Expenses
Indemnity
Removal of apparatus
Enactments and agreements
Co-operation
Access
Arbitration
The provisions of this Part have effect unless otherwise agreed...
In this Part— “the 2003 Act” means the Communications Act...
The exercise of the powers conferred by article 29 (statutory...
(1) Subject to sub-paragraphs (2) to (4), if as a...
The provisions of this Part have effect unless otherwise agreed...
In this Part— “asset protection agreement” means an agreement to...
Facilities and rights for alternative apparatus
(1) Where under this Part Network Rail is required to...
(1) The undertaker must not exercise the powers conferred by—...
(1) The undertaker must before commencing construction of any specified...
(1) Any specified work and any protective works to be...
The undertaker must— (a) at all times afford reasonable facilities...
Network Rail must at all times afford reasonable facilities to...
(1) If any permanent or temporary alterations or additions to...
The undertaker must repay to Network Rail all reasonable fees,...
(1) In this paragraph— “EMI” means, subject to sub-paragraph (2),...
If at any time after the completion of a specified...
Retained apparatus
The undertaker must not provide any illumination or illuminated sign...
Any additional expenses that Network Rail may reasonably incur in...
(1) The undertaker must— (a) pay to Network Rail all...
Network Rail must, on receipt of a request from the...
In the assessment of any sums payable to Network Rail...
The undertaker and Network Rail may, subject in the case...
Nothing in this Order, or in any enactment incorporated with...
The undertaker must give written notice to Network Rail where...
The undertaker must, no later than 28 days from the...
Application
Expenses and costs
Interpretation
Consent for specified works
(1) The undertaker must not under the powers of this...
(1) The undertaker must give to the Company not less...
(1) The undertaker must not exercise the powers conferred by...
To ensure its compliance with this Part, the undertaker must...
The undertaker and the Company must each act in good...
Expenses
Indemnity
Arbitration
(1) Subject to sub-paragraphs (2) and (3), if by reason...
The provisions of this Part have effect unless otherwise agreed...
In this Part— “OPNMP” means Offshore Piling Noise Monitoring Plan,...
(1) Prior to the commencement of any offshore piling as...
(1) The undertaker may, at any time following approval of...
The authorised development must be carried out in accordance with...
The undertaker will give Conwy County Borough Council not less...
Nothing in any OPNMP may conflict with requirement 4 of...
Any approval required under this Part must not be unreasonably...
Any difference or dispute arising between the undertaker and Conwy...
For the protection of Wales and West Utilities as referred...
Interpretation
Applications made under requirements
Further information
Provision of information by Consultees
Fees
Appeal
Primary objective
Time periods
Timetable
Procedure
Arbitrator’s powers
Costs
Confidentiality
Authority to survey and investigate the land
- Serve 14 days' notice and obtain consent before surveying land
Browse 43 other sections — procedural / definitional / commencement
Citation and commencement
Interpretation
Development consent etc. granted by the Order
Operation of generating station
Power to maintain the authorised development
Benefit of the Order
Application and modification of legislative provisions
Defence to proceedings in respect of statutory nuisance
Street works
Application of the 1991 Act
Temporary stopping up of rights of way
Temporary restriction of use of streets
Access to works
Discharge of water
Protective works to buildings
Removal of human remains
Compulsory acquisition of land
Time limit for exercise of authority to acquire land compulsorily
Compulsory acquisition of rights
Compulsory acquisition of land: minerals
Private rights
Application of the 1981 Act
Acquisition of subsoil only
Modification of Part 1 of the 1965 Act
Rights under or over streets
Temporary use of land for carrying out the authorised development
Temporary use of land for maintaining the authorised development
Statutory undertakers
Recovery of costs of new connections
Funding
Application of landlord and tenant law
Felling or lopping of trees and removal of hedgerows
Trees subject to tree preservation orders
Abatement of works abandoned or decayed
Saving provisions for Trinity House
Crown rights
Protective provisions
Operational land for the purposes of the 1990 Act
Certification of plans, etc.
Service of notices
No double recovery
Requirements, appeals, etc.
Arbitration
Explore more
Browse legislation
Find other UK business legislation with related guidance.